Legal

Terms & Conditions

Last updated: August 2026

This is a template terms & conditions document provided for demonstration purposes. Before publishing, have it reviewed by a qualified legal professional so it accurately reflects your actual business terms, pricing structure, and warranties.

1. Acceptance of Terms

By accessing or using this website, or engaging DesignScapes for design and decor services, you agree to be bound by these Terms & Conditions.

2. Our Services

DesignScapes provides turnkey design and decor solutions for residential, commercial, and outdoor spaces, including design consultation, space planning, 3D visualization, material selection, procurement, execution, and project management, as described on this website.

3. Consultations & Quotes

Free consultations booked through this website are subject to availability. Any design proposal, quote, or estimate provided is indicative and subject to change following a detailed site visit and scope discussion.

4. Project Engagement

A formal project agreement, including scope of work, timelines, and payment schedule, will be signed separately before execution begins. These website Terms do not constitute that agreement.

5. Payments

Payment terms, milestones, and applicable taxes will be defined in the project agreement. Any delay in agreed payments may affect project timelines.

6. Timelines

While we work to realistic, agreed timelines, project schedules may be affected by factors outside our control, including material availability, site conditions, and client-requested changes.

7. Intellectual Property

Design concepts, 3D visualizations, and drawings created by DesignScapes remain our intellectual property until full payment is received and are not to be reproduced or shared with third parties without consent.

8. Limitation of Liability

DesignScapes is not liable for delays or issues arising from circumstances beyond our reasonable control, including but not limited to third-party vendor delays, force majeure events, or client-side approvals.

9. Website Use

Content on this website is for general informational purposes only and may be updated without notice. Submitting a form on this site does not create a binding service agreement.

10. Governing Law

These Terms are governed by the laws of India, and any disputes shall be subject to the jurisdiction of the courts in Delhi NCR.

11. Contact Us

Questions about these Terms can be directed to:

📞 8796542707 · ✉ contact@designscapes.in